By cmsifyAdmin, 31 January, 2025 View Node 36.206 Liquidated damages. 36.206 Liquidated damages. The contracting officer must evaluate the need for liquidated damages in a construction contract in accordance with 11.502 and agency regulations. Parent topic: Subpart 36.2 - Special Aspects of Contracting for Construction Log in or register to post comments Comments
36.206 Liquidated damages. The contracting officer must evaluate the need for liquidated damages in a construction contract in accordance with 11.502 and agency regulations. Parent topic: Subpart 36.2 - Special Aspects of Contracting for Construction
36.206 Liquidated damages. The contracting officer must evaluate the need for liquidated damages in a construction contract in accordance with 11.502 and agency regulations. Parent topic: Subpart 36.2 - Special Aspects of Contracting for Construction
Comments